1. Agreement to Terms
By accessing and using the Whizpool Properties website (whizpoolproperties.com) and related services provided by Whizpool Builders & Construction ("we", "our", or "us"), you agree to be bound by these Terms of Service. If you do not agree with any part of these terms, you may not use our website or services.
2. Services Offered
Whizpool Builders provides the following services through this website:
- Construction Cost Calculator: Interactive tool for estimating per-square-foot construction costs. Estimates are indicative and subject to site-specific assessments.
- Project Showcase: Display of ongoing and completed construction projects with progress tracking.
- Contact & Inquiry Forms: Lead capture forms for scheduling consultations and live video call site tours.
- AI Construction Advisor: Automated chat assistant for general construction-related queries.
- Blog & Guides: Informational content about Pakistan real estate, construction best practices, and investment advice.
Note: This website does not constitute a formal construction contract. All construction agreements, Bill of Quantities (BOQ), milestone payment schedules, and engineering specifications are formalized through separate written contracts.
3. Construction Estimates Disclaimer
All construction rates, cost estimates, and material specifications displayed on this website (including the Construction Cost Calculator) are indicative only and subject to change based on:
- Current market prices of raw materials (steel, cement, bricks, tiles, etc.)
- Site-specific conditions (soil type, access, plot elevation)
- Society/authority requirements (CDA, RDA, Bahria Town, DHA regulations)
- Design complexity and customization preferences
Final pricing is confirmed only through a formal, signed construction agreement with detailed BOQ.
4. User Obligations
When using this website, you agree to:
- Provide accurate and complete information in all forms and communications.
- Not misuse the website for fraudulent purposes or unauthorized data scraping.
- Not reproduce, distribute, or commercially exploit content from this website without written permission.
- Use the AI chat advisor for informational purposes only — it does not constitute professional engineering or legal advice.
5. Overseas Client Provisions
For clients residing outside Pakistan ("Overseas Clients"), the following additional terms apply:
- All construction agreements are governed by the laws of the Islamic Republic of Pakistan.
- Milestone payments must be made to verified company bank accounts only. We never accept payments via personal accounts, cash agents, or informal hawala channels.
- Live video call site tours are scheduled at mutually agreed times across time zones and are subject to weather and site access conditions.
- Society NOC and map approval timelines are dependent on the respective authority and are outside our direct control.
6. Intellectual Property
All content on this website — including but not limited to text, images, logos, 3D renderings, floor plans, blog articles, and the "Whizpool" brand identity — is the intellectual property of Whizpool Builders & Construction and is protected under applicable copyright and trademark laws.
7. Limitation of Liability
Whizpool Builders shall not be held liable for:
- Decisions made based on indicative cost estimates from the website calculator.
- Delays caused by government authorities, force majeure, or material supply disruptions.
- Losses arising from unauthorized use of our website or communications.
- Third-party content linked from this website.
8. Dispute Resolution
Any disputes arising from these terms or your use of this website shall be resolved through good-faith negotiation. If unresolved, disputes shall be submitted to the courts of Islamabad, Pakistan, which shall have exclusive jurisdiction.
9. Changes to Terms
We reserve the right to modify these Terms of Service at any time. Changes will be posted on this page with an updated effective date. Continued use of the website after changes constitutes acceptance of the revised terms.
10. Contact
For questions regarding these Terms of Service, contact:
Whizpool Builders & Construction
Plaza 45, Main Expressway, Gulberg Greens, Islamabad, Pakistan
Email: info@whizpoolhomes.com
Phone: +92 51 111 944 977